1987第3版-YB黄皮书-电气与机械工程合同条件英文.doc
- 文档编号:1301233
- 上传时间:2022-10-20
- 格式:DOC
- 页数:64
- 大小:505KB
1987第3版-YB黄皮书-电气与机械工程合同条件英文.doc
《1987第3版-YB黄皮书-电气与机械工程合同条件英文.doc》由会员分享,可在线阅读,更多相关《1987第3版-YB黄皮书-电气与机械工程合同条件英文.doc(64页珍藏版)》请在冰豆网上搜索。
FEDERATIONINTERNATIONAEDESINGENIEURE-CONSEILS
CONDITIONSOFCONTRACTFORELECTRICALANDMECHANICALWORKS
电气与机械工程合同条件(1987第三版)
1988年修订
黄皮书
INCLUDINGERECTIONONSITE
WITHFORMSOFTENDERANDAGREEMENT
THIRDEDITION1987
REPRINTED1988WITHEDITORIALAMENDMENTS
PREAMBLE
ThisPreamblemustbecompletedinallcasesreferringtocompletedscheduleswhereappropriate.Whencompleted,thisPreamble,theGeneralConditions,Specification,Employer'sandContractor'sDrawings,SchedulesandotherdocumentscanconstituteacontractonthebasisoftheGeneralConditionsinPartI.Ifthisisnotwhatisrequired,PartIImustalsobecompleted.
CommencementDate
Sub-Clause1.1.1.(i)
ThedateforcommencementoftheWorksis.
TheEmployer
Sub-Clause1.1.12.
TheEmployeris.
TheEngineer
Sub-Clause1.1.15.
TheEngineeris.
TimeforCompletion
Sub-Clause1.1.1.35.
TheTimeforCompletionisdaysfromtheCommencementDate.
Contractor'sProfit
Sub-Clause1.6
Thepercentagetocoverprofitentitlement,whereappropriate,is%.
RulingLanguage
Sub-Clause5.1
Theversioninlanguage(rulinglanguage)shallprevail.
DaytoDayCommunications
Sub-Clause5.2.
Thelanguagefordaytodaycommunicationsis.
ProgrammetobeFurnished
Sub-Clause12.1.
TheProgrammemustbesubmittedintheformof.
Electricity,Water,GasandOtherServices
Sub-Clause14.3.
SuppliesontheSiteare:
.
a.Electricity:
.
b.Water:
.
c.Gas:
.
d.Otherservices:
.
Employer'sEquipment
Sub-Clause14.4.
ThefollowingEmployer'sequipmentisavailableforusebytheContractorundertheEmployer'soperation:
.
WorkingHours
Sub-Clause18.3
Thenormalworkinghoursare.
DelayinCompletion
Sub-Clause27.1
FailuretomeettheTimeforCompletionentitlestheEmployertoreductioninContractPriceasfollows:
Percentageperday%
Maximum%
ProlongedDelay
Sub-Clause27.2.
MaximumamountrecoverablefromtheContractorbytheEmployer:
.
TermsofPayment
Sub-Clause33.1.
InadditiontotheprovisionsunderClause33,thetermsofpaymentshallbe:
.
PaymentinForeignCurrencies
Sub-Clause35.1.
Paymentinforeigncurrenciesshallbearrangedasfollows:
.
RatesofExchange
Sub-Clause35.3.
TheratesofexchangeforthepurposeoftheContractare:
.
PaymentagainstProvisionalSums
Sub-Clause36.4.(b)
ThepercentagetobeappliedtoProvisionalSumsshallbe%
MaximumLiability
Sub-Clause42.2.
ThemaximumliabilityoftheContractortotheEmployershallbe.
InsuranceofWorks
Sub-Clause43.1.
ThededuciblelimitsintheinsurancecoveroftheWorksshallnotexceed.
Sub-Clause43.1.(a)
Theadditionalriskstobeinsuredare:
.
ThirdPartyLiability
Sub-Clause43.3.
TheamountofinsuranceagainstthirdpartyliabilitytakenoutbytheContractorshallnotbelessthan:
.
PaymentonTerminationforEmployer'sDefault
Sub-Clause46.3.
TheadditionalamountpayablebytheEmployeronterminationshallnotexceed:
.
Labour,MaterialsandTransport
Sub-Clause47.1.
Themethodofcalculatingadjustmentsforchangesincostsshallbe:
.
NoticestoEmployerandEngineer
Sub-Clause49.2.
TheaddressoftheEmployerfornoticesis:
.
TheaddressoftheEngineerfornoticesis:
.
ApplicableLaw
Sub-Clause51.1.
Theapplicablelawislaw.
ProceduralLawforArbitration
Sub-Clause51.2.
Theprocedurallawforarbitrationis
LanguageandPlaceofArbitration
Sub-Clause51.3.
Thelanguageofarbitrationislanguage.
Theplaceofarbitrationis.
PARTI:
GENERALCONDITIONS
DefinitionsandInterpretations
Definitions
1.1
IntheContract(ashereinafterdefined)thefollowingwordsandexpressionsshallhavethemeaningsherebyassignedtothem:
1.1.1
"CommencementDate"meanswhicheveristhelatestof:
i)thedatespecifiedinthePreambleasthedateforcommencementoftheWorksorthedatewhentheContractorreceives:
ii)suchpaymentinadvanceofthecommence
- 配套讲稿:
如PPT文件的首页显示word图标,表示该PPT已包含配套word讲稿。双击word图标可打开word文档。
- 特殊限制:
部分文档作品中含有的国旗、国徽等图片,仅作为作品整体效果示例展示,禁止商用。设计者仅对作品中独创性部分享有著作权。
- 关 键 词:
- 1987 YB 黄皮书 电气 机械工程 合同 条件 英文